- (1.) The question raised in this appeal is whether any interference is called for with the award dated 29th June, 2003 on the basis of objections of the Appellant-State of Orissa.
(2.) The Respondent-Company ("the Contractor") was awarded the work of "Construction of Mahanadi Barrage on the Right Side from the Right Divide Wall including Right Head Regulator" vide Agreement dated 11th February, 1986 at approximate cost of Rs. 5 crore. The project was to be completed by 11th November, 1987. However, within the said period only 24.99% work was executed. Further extension of time was granted upto 21st March, 1988. Till then, only 36.81% of the work was executed. In these circumstances, vide letter dated 21st April, 1988, the contract was terminated under Clause 46 of the General Conditions of Contract. The work executed till then was only 47.67%.
(3.) The Contractor made a claim for Rs. 6.99 crore towards its dues. The dispute was referred to the Arbitration. Retired Justice B.K. Behera ('the Arbitrator') vide award dated 29th June, 2003 upheld the claim of the Contractor to the extent of Rs. 4.45 crore. The Arbitrator also allowed counter claim of the Department to the extent of Rs. 1.37 crores.;